Terms & Conditions

 

Thank you for accessing WebdesignMe (webdesign-me.co.uk, webdesignme.co.uk).

The information on our website has been prepared to ensure that your experience of the site is one you will want to repeat

Please note that the below use of words on this page stands as follow:

"WebdesignMe" or “us” or “we” "our" or "webdesignme.co.uk" or "webdesign-me.co.uk" refers to the owner of the website.

"Buyer" refers to the company, firm, body, person or individual purchasing the services from WebdesignMe.

"Quotation" is a verbal or written agreement confirming works to be carried out, price and terms & conditions provided by WebdesignMe to the Buyer.

"Contract" is a written agreement between WebdesignMe and the Buyer, detailing the scope of the works & services, price and terms & condtions of the services being offered by Webdesignme to the Buyer. Should the Buyer breach any part of the contract, WebdesignMe reserves the right to stop or cancel works at any time.

"Order" is a verbal or written agreement, showing acceptance of our Quotation, from the Buyer in respect of the services agreed, submitted to WebdesignMe.

"Services" refers to the scope of works or service or any of them to be performed by WebdesignMe for the Buyer following an Order.

"Order Form" refers to WebdesignMe standard form of Order.

 

GENERAL

A Quotation is not a contract and WebdesignMe reserves the right to change or alter a submitted Quotation at any time, without any notice. A Quotation is valid for 21 days from the date shown on the Quotation unless otherwise agreed.

Any Contract between WebdesignMe and the Buyer will be subject to the terms and conditions on this page. All terms and conditions appearing or referred to in the Order or otherwise stipulated by the Buyer shall have no effect, unless such Order is in "Our Order Form". Any variation to the Contract must be confirmed in writing by WebdesignMe.

The same way these conditions apply to services, to the extent applicable, they apply to goods & products offered by WebdesignMe as well.

The minimum period of any ongoing offered services purchased will be for 12 months.

All projects & services offered by WebdesignMe are subject to the terms & conditions on this page as standard plus any other terms as per the Order at any particular time.

 

PRICES

All prices are subject to terms & condtions on the provided Quotation and this page.

 

TERMS OF PAYMENT

A non-refundable 25% deposit is required before any commencement of agreed works as per the Order.

WebdesignMe will invoice the Buyer for all services (less any paid deposit) immediately on completion of web site.

Payment made by the Buyer to WebdesignMe needs to be in the following forms: cash or cheque or transfer directly to WebdesignMe bank account or by arranged direct debit.

If the Buyer fails to make payment of any amount due to WebdesignMe under this Agreement on the relevant due date, default interest at the rate specified by the Late Payment of Commercial Debts (Interest) Act 1998 shall be added to such amount for the period from the day after the due date until the date of receipt (whether before or after judgment) together with any reasonable and proper amounts incurred by WebdesignMe in seeking to recover such late payment from the Buyer (including, without limitation, legal fees).

 

WEBSITE DESIGN

All creation files remain the intellectual property of WebdesignMe on completion of any particular web design project.

The Buyer/Client unconditionally guarantees that any text, photos, artworks or graphics supplied to WebdesignMe for their web design project are owned by the client; or the client has the necessary permission to use any such materials. WebdesignMe will not be hold responsible for any claim or suit arising from the use of these materials supplied by Buyers/Clients.

WeddesignMe shall be free to use, disclose, display, perform, transmit, exhibit, reporduce, create derivatives works and distribute any such item from clients/customers web pages unless otherwise agreed. WebdesignMe shall also be free to use any ideas, concepts, skills & techniques in the building of websites for any othe purpose whatsoever including but not limited to developing, manufacturing and marketing products and any other items incorporating such information unless otherwise agreed.

 

WEBSITE OPTIMISATION

Although WebdesignMe will try to improve a particular client web site's position and ranking in the search engines results for particular keyword(s), we do not warrant that this effort is in any way guaranteed.

WebdesignMe will not be held responsible for any changes in your search engines ranking or position for a particular search term.

 

WEB SUPPORT SERVICES

WebdesignMe is a registered reseller for domain name registration, website & email hosting through 1&1 (1 and 1). Please note any registration of domain name(s), hosting of web site(s) or mailbox(es) registration on behalf of the Buyer/Client is subject to 1 and 1 terms and conditions.

WebdesignMe will accept no liability for any financial loss resulting from the server being down and hence website being unavailable for a minimum of 36 hours.

WebdesignMe will accept no liability for any financial loss resulting from a domain name or domain names not being renewed.

WebdesignMe will accept no liability for any financial loss resulting from any registered mailbox not being available.

A charge of £80.00 will be charged for any particular domain name transfer. This is applicable as long as any other outstanding balance owed has been settled.

 

DEPOSIT

Payment can be made in the following ways: cash or cheque or transfer directly to WebdesignMe bank account or by arranged direct debit.

A non-refundable 25% deposit is required before any commencement of agreed works.

 

LIMIT OF RESPONSIBILITY & WARRANTY

WebdesignMe acknowledges and agrees that any undertaken works will be carried in accordance with good industry practice, with reasonable skill & care, within a reasonable period of time.

The Buyer acknowledges and agrees that WebdesignMe will have no liability to the Buyer/Client/Customer in respect to the ranking and positioning of the web site.

In any circumstances, WebdesignMe will not be liable to the Buyer for any indirect or consequential losses or any loss of profits purported to have been suffered by the Buyer.

In any circumstances, WebdesignMe will not be liable to the Buyer for failure in the performance of any of its obligations under the agreement caused by factors beyond or outside our control.

The Buyer remedies in respect of any claim under the foregoing express warranty or any condition or warranty implied by law or any other claim in respect of the Services or Web Site or any workmanship in relation to them (whether or not involving negligence on the part of WebdesignMe) will, in all cases, be limited to re-performance of the Services or refund of the relevant purchase price.

 

TIMESCALE & COMPLETION DATES

Once signed Order is received from the Buyer, we endeavour to complete our services within 30 days depending on the size of your project; however we could not guarantee this if delays have resulted in us receiving necessary materials from the Buyer.

The completion date of any project(s) and services are approximate unless otherwise stated and agreed.

WebdesignMe will not be liable in any circumstances for the consequences of any delay in delivery, performance or failure to deliver due to negligence of the Buyer.

No delay (unless material) shall entitle the Buyer to reject any delivery or performance or any other Order from the Buyer or to repudiate the Contract or the Order.

 

RESPONSIBILITY FOR THE WEBSITE APPROVAL

The Buyer acknowledges and agrees that Webdesignme will produce content of the website based on information provided by the Buyer.

The Buyer will be resposible to review, check and approve the content of the Website (including, without limitation, spelling of names, addresses and accuracy fo telephone & fax numbers and email addresses) at the time of the completion of aby web design project. WebdesignMe will not be held responsible for any of these errors after completion.

WebdesignMe will have no liability to the Buyer for any inaccuracies in the Web Site if and to the extent that the Buyer has failed to review and/or approve (or require amendment (as the case may be)) provided to the Buyer by WebdesignMe pursuant to this Agreement.

 

TERMINATION

WebdesignMe reserves the right to terminate the Contract immediately in the event that the Buyer is in breach of its obligations under the Contract and/or the Buyer suffers any event of insolvency or is or becomes unable to pay its debts as they fall due.

WebdesignMe may at its discretion suspend or terminate the supply of any goods and services if the buyer fails to make any payment when due or otherwise defaults in any of its obligations under the contract or any other agreement with WebdesignMe or becomes insolvent, has an administrative receiver appointed of its business or is compulsorily or voluntarily wound up or WebdesignMe believes that any of those events may occur and in any case of termination may forfeit any monies paid.

In the event of liquidation or insolvency from the Buyer, unless project and services paid in full, WebdesignMe reserves the right of retaining complete pocession of any particular project.

Any contract cancelled by the Buyer during the first 12 months (first year) will incure a penalty charge of £150 (one hundred and fifty pounds)

WebdesignMe may by written notice terminate the Agreement immediately and without liability for compensation or damages except as mentioned in this agreement if the Buyer fails to make payment as specified above.

Please note that domain name(s) remain the property of WebdesignMe on termination and closure of any particular contract.

 

THIRD PARTY CLAIMS

The Buyer willl indemnify WebdesignMe and keep WebdesignMe indemnified from and against any and all actions, costs (including, without limitation, the cost of defending any legal proceedings), claims, proceedings, accounts and damages in respect of any infringement or alleged infringement by a third party of any patent, registered design, unregistered design, design right, copyright, trade mark or other industrial or intellectual property rights resulting from compliance by WebdesignMe with the Buyer's instructions, whether express or implied.

 

THIRD PARTY RIGHTS

A person who is not party to this agreement shall have no right under the Contracts (Rights of Third Parties) Act 1999 to enforce any term of this agreement. This clause does not affect any right or remedy of any person which exists or is available otherwise than pursuant to that Act.

 

SUB-CONTRACTORS INVOLVEMENT & ASSISGNMENT

The Web Site shall be for the sole use of the Buyer and shall not be capable of assignment to a third party by the Buyer. Under the Contract, the Buyer has no rights or obligation to assign or transfer in whole or in part any project without the prior written consent of WebdesignMe.

WebdesignMe reserves the right to sub-contract any work relating to the Contract without obtaining the consent of, or giving notice to, the Buyer.

 

NOTICES

Any notice or other communication to be given under these conditions must be in writing and may be delivered or sent by prepaid first class letter post or facsimile transmission.

Any notice or document shall be deemed served: if delivered, at the time of delivery; if posted, 48 hours after posting; and if sent by facsimile transmission, at the time of transmission.

 

INVALIDITY

The invalidity, illegality or un-enforceability of any provision of these conditions should not affect the other conditions.

 

JURISDICATION & LAW

The Contract shall be governed by and construed in all respects in accordance with English law and the parties hereby submit to the exclusive jurisdiction of the English courts.